Flooring Contract
Jim Clark Contractors
Free Template
Flooring Contract Template
Updated August 29, 2025
A flooring contract is a formal agreement between a client and a contractor that outlines the flooring type, installation process, materials, project timeline, and costs for a renovation project. A clear, written contract defining expectations minimizes surprises and costly changes.
Who Needs a Flooring Contract?
Whether you’re a contractor or new homeowner, establishing a flooring contract is a practical safeguard for both parties. This agreement helps keep both people accountable, and sets clear guidelines for how flooring renovations should be completed efficiently and safely.
There are multiple types of projects where you’ll want to have a contract in place:
- Residential flooring installation: Ensures the homeowner or landlord knows exactly what they're getting, and how much they’re paying upfront.
- Commercial flooring projects: Large-scale projects like carpet in office buildings or vinyl flooring in retail spaces require much more attention to detail and money, making an agreement even more important.
- Flooring repairs and renovations: Even small repair jobs should be covered by a contract, to ensure the client’s happy with the results.
- Custom flooring jobs: For detailed, intricate jobs with specialty products, clearly outlining the sourcing of materials, price, and availability is key!
What Are Some Common Terms of a Flooring Contract?
Here’s some common sections and terms you’ll probably see in a residential or commercial flooring contract:
- Scope of services: Covers the details of the job, like where the new flooring will be installed, services provided (such as prepping the sub-floor for new flooring), flooring removal, leveling the floor, and Materials: Who’s responsible for purchasing the materials? Also, include details like flooring color, style, brand and exact square footage needed.
- Installation method:To avoid any misunderstandings and to ensure client satisfaction, determine which of these common installation methods will be used:
- Glue-down: a strong bond between flooring and sub-floor
- Floating: a cushioned installation for a smoother feel
- Nail-down: a secure fastening for maximum durability
- Timeline: Include the installation plan from start to end, as well as guidelines for unexpected challenges like bad weather or supply chain issues.
- Payment terms: Include a quote (with room for unexpected expenses), upfront costs or deposits, milestone payments, how the invoice will be delivered, and which payment methods are accepted.
- Warranties: Include any warranties or guarantees that come with the materials or the installation, which helps to protect the client in case of defects or poor workmanship in the installation process.
- Cleanup and disposal: Something not everyone thinks of is who's responsible for cleaning up the workspace, and disposing of waste materials like old flooring, packaging, and other debris.
- Permits and approval: Outline the standard operating procedure for acquiring the necessary permits or approvals from local authorities.
- Liability and insurance: Cover your bases by including the contractor's insurance coverage, along with clearly outlining who is responsible if flooring is damaged or someone gets hurt during the project?
Include an Estimate or Quote for Your Project
A detailed estimate quote gives your client a clear picture of what to budget for their flooring project. It breaks down labor, materials, and any extras. Quoting your price and timeline offers transparency and shows your client you're upfront and honest. Be sure to include a clause in the quote that allows for estimated adjustments if unexpected costs pop up, too.
-
-
Flooring Contract
Jim Clark Co.
AgreementThis Flooring Installation Contract ("Agreement") is made and entered into on , by and between:
Participants-
-
Flooring ContractorJim Clark3445 Ravenwood DrCollege Park, GA 30349(404) 763-3294
Terms1. Property Description: The flooring installation will take place at the following location: .
2. Grant of Access: The Property Owner grants the Flooring Contractor and any subcontractors access to the property to perform the agreed-upon flooring installation work. Access will be granted during the following days and times: . Tools, materials, and equipment may be stored in the following locations: .
3. Right to Inspect: The Property Owner retains the right to inspect the work at any reasonable time to ensure compliance with the terms of this Agreement.
4. Scope of Work:
The Flooring Contractor agrees to perform the following flooring installation work:
- Flooring Type: .
- Materials: .
- Installation Details: .
- Cleanup: The Contractor will be responsible for cleaning up the work area after the installation is complete.
5. Project Timeline:
- Installation Start Date:
- Expected Completion Date:
- Project Timeline: The project will follow this timeline: .
6. Price and Payment Terms:
- Total Project Price:
- Deposit:
- Payment Schedule: Payments will be made as follows: .
- Payment Methods: Acceptable methods of payment include .
- Late Payment Policy: Late payments will incur a fee of .
- Lien Policy: The Flooring Contractor reserves the right to file a lien on the property for any unpaid balance after 30 days from the due date.
7. License, Permit, and Insurance Requirements:
- Licenses and Permits: The Flooring Contractor will obtain all necessary licenses and permits to perform the work.
- Insurance: The Flooring Contractor will maintain appropriate insurance coverage, including general liability and workers' compensation insurance. Proof of insurance will be provided to the Property Owner upon request.
8. Unforeseen Circumstances/Acts of God: Neither party will be held liable for failure to perform their obligations under this Agreement due to unforeseen circumstances or acts of God (e.g., natural disasters, severe weather, pandemics).
9. Hidden Defects: If the Flooring Contractor discovers any hidden defects or hazardous conditions (e.g., mold, asbestos, subfloor issues) during the installation, work will be halted immediately, and the Property Owner will be notified. The parties will then agree on the necessary repairs and any additional costs or changes to the timeline.
10. Amendments: This Agreement may be amended only by a written document signed by both parties. Any changes must be discussed and agreed upon before they take effect.
11. Termination:
- By Either Party: Either party may terminate this Agreement with written notice.
- For Cause: Either party may terminate this Agreement immediately if the other party breaches any material provision and fails to cure such breach within 10 days after receiving written notice of the breach.
12. Warranties:
The Flooring Contractor provides the following warranties for the work performed:
- Workmanship Warranty: .
- Materials Warranty: .
13. Dispute Resolution and Remedies:
- Negotiation: The parties will first attempt to resolve disputes through informal negotiation.
- Mediation: If negotiation fails, the parties agree to attempt mediation.
- Arbitration: If mediation fails, disputes will be resolved through binding arbitration under the rules of the American Arbitration Association.
- Governing Law: This Agreement will be governed by the laws of the state where the property is located.
14. Indemnification: Each party agrees to indemnify and hold harmless the other party from any claims, damages, or liabilities arising out of the performance of this Agreement, except in cases of gross negligence or willful misconduct.
15. Attachments:
The following documents are attached to and form part of this Agreement:
- Blueprints:
- Diagrams:
- Spec Sheets:
- Other Attachments:
16. Signatures: By signing below, the parties agree to the terms and conditions outlined in this Flooring Installation Contract.
This Agreement constitutes the entire agreement between the parties and supersedes all prior negotiations, representations, or agreements, whether written or oral. This Agreement may be executed in counterparts, each of which shall be deemed an original, but all of which together shall constitute one and the same instrument.
Signatures-
Click to signJohn Doe
-
Click to signJim Clark
-
